Terms & Conditions

​

1. Payment Terms 3.1. Payments shall be made according to the schedule outlined in the contract. A deposit may be required before work begins, not to exceed 10% of the contract amount or $1,000, whichever is less, as per California law (Business and Professions Code § 7159). 3.2. Progress payments will be invoiced based on completed milestones or as specified in the contract. Final payment is due upon project completion, subject to a final walkthrough and approval by the Client. 3.3. Late payments will incur a late fee of 1.5% per month on the outstanding balance, unless prohibited by law. The Company reserves the right to suspend work if payments are not made as agreed. 3.4. All payments shall be made via check, bank transfer, or other methods specified in the contract. The Client is responsible for any transaction fees.
    

2. Project Execution 4.1. The Company will perform services in a professional manner, in accordance with industry standards and applicable building codes. All work will be performed by personnel holding a valid California Contractor License (License #1137171) or appropriate subcontractor licenses. 4.2. Estimated completion dates are provided as a good-faith estimate and are not guaranteed. Delays due to weather, material shortages, permitting issues, or other factors beyond the Company’s control will not constitute a breach of contract. 4.3. The Client shall provide safe and unobstructed access to the work site, including necessary utilities (e.g., water, electricity), unless otherwise agreed. 4.4. The Client is responsible for obtaining any required homeowner permits, unless the Company is expressly contracted to do so.
    

3. Materials and Equipment 5.1. The Company will supply materials as specified in the contract. Any Client-provided materials must meet industry standards and be approved by the Company. The Company is not liable for defects or delays caused by Client-provided materials. 5.2. All equipment and tools used by the Company remain the property of the Company or its subcontractors.
    

4. Warranties 6.1. The Company warrants its workmanship for a period specified in the contract, in accordance with California law. Material warranties are limited to those provided by the manufacturer or supplier. 6.2. Warranty claims must be submitted in writing within the warranty period. The Company will repair or replace defective work caused by its error at no additional cost, subject to the terms of the contract. 6.3. Warranties do not cover damage caused by misuse, neglect, or modifications by the Client or third parties.
    

5. Liability and Insurance 7.1. The Company maintains general liability insurance and workers’ compensation insurance as required by California law. Certificates of insurance are available upon request. 7.2. The Company is not liable for indirect, incidental, or consequential damages, including but not limited to loss of use or property damage, except as required by law. 7.3. The Client is responsible for maintaining adequate property insurance to cover their premises and belongings during the project.
    

6. Termination 8.1. Either party may terminate the contract with written notice if the other party materially breaches the agreement and fails to remedy the breach within seven (7) days. 8.2. Upon termination, the Client shall pay for all work performed, materials ordered, and costs incurred up to the termination date. Deposits are non-refundable, except as outlined in the Refund Policy. 8.3. The Company may terminate the contract immediately if the Client fails to make payments or provide site access as agreed.
    

7. Dispute Resolution 9.1. Any disputes arising from the contract or these Terms shall first be addressed through good-faith negotiation. If unresolved, disputes will be submitted to mediation in Los Angeles County, California. 9.2. If mediation fails, disputes shall be resolved through binding arbitration in accordance with the rules of the American Arbitration Association, unless otherwise required by law. 9.3. The prevailing party in any dispute shall be entitled to recover reasonable attorney’s fees and costs, as permitted by law.
    

8. Force Majeure The Company shall not be liable for delays or failure to perform due to events beyond its reasonable control, including but not limited to natural disasters, labor strikes, or government actions.
    

9. Governing Law These Terms and all contracts are governed by the laws of the State of California. Any legal action shall be filed in Los Angeles County, California, unless otherwise required by law.
    

10. Miscellaneous 12.1. These Terms, together with the written contract, constitute the entire agreement between the Company and the Client, superseding any prior agreements or understandings. 12.2. The Company reserves the right to update these Terms at any time. Updated Terms will apply to new contracts signed after the effective date. 12.3. If any provision of these Terms is found to be invalid or unenforceable, the remaining provisions shall remain in full force and effect.